World Library  


Government Caused Delays in the Performance of Federal Contracts the Impact of the Contract Clauses

By Clark, Robert B., Major

Description
Military Law Review

Excerpt
Introduction: It has been said that delays in the performance of Government contracts have accounted for more losses and a greater percentage of business failure than any other single factor in the field of Government procurement.' We are all aware of the example of the over optimistic or inefficient contractor who is forced to pay liquated damages because he has not been able to complete his work on time, but the contractor is not the only party who can cause delays. In a surprising number of cases it is the Government, rather than the contractor, who is responsible for a work stoppage. The Court of Claims has been called upon over one hundred times to decide claims based upon Government-caused delays. The various administrative boards established to handle factual disputes under Government contracts are continually required to resolve disputes arising from delays caused by the Government. As will be seen, the problem has significance for both parties to the contract

Table of Contents
TABLE OF LEADING ARTICLES AND COMMENTS-AUTHORS Adkins, First Lieutenant Allan B., Recent Developments- Instructions on the Sentence_______-___-_-__---___--_____-___-__l4/Anderson, Captain Richard G., Article 123(a) : A Bad Check Offense for the Military _-_____________________________1_7_/_1 45 Avins, Alfred, A History of Short Desertion ________________________ 13/143 Baldwin, Captain Gordon B., A New Look at the Law of War: Limited War and Field Manual 27-10 ____________________________ 4/1 Barrett, First Lieutenant Michael F., Jr., A Supplemellt to the Survey of Military Justice ________________________________ 20/107 Bednar, Captain Richard J., Discharge and Dismissal as Punishment in the Armed Services ____________________________ 16/1 Bookout, Lieutenant Colonel Hal H., Conflicting Sovereignty Interests in Outer Space: Proposed Solutions Remain in Orbit! ______________ 7/23 Cabell, Major Henry B., Damnosa HereditasSpecial Courts-Martial_- 7/146 Chermak, Lawrence E., Financial Control: Congress and The Executive Branch_____-____-_-___________--____--___--_____Chermak, Lawrence E., The New Defense Programming Concept-__-__l8/141 Chilcoat, Major William J., Presentencing Procedure in Courts-Martial- 9/127 Clarke, Major Robert B., Government-Caused Delays in the Performance of Federal Contracts: The Impact of the Contract Clauses- .---22/1 Clause, Captain James D., The Status of Deserters Under the 1949 Geneva Prisoner of War Convention _________________________ 11/15 Clausen, Captain Hugh J., Rehearings Today in Militmy Law________12/146 Cobbs, Cabell F., The Court of Military Appeala and the Defense Counsel_ ________________________________________1_2/-1_3 1 Cobbs, Captain Cabell F., Military Searches and Seizures ____________- 1/1

Click here to view

Book Id: WPLBN0000701142
Format Type: PDF eBook
File Size: 2.82 MB.
Reproduction Date: 2005
Full Text


Title: Government Caused Delays in the Performance of Federal Contracts the Impact of the Contract Clauses  
Author: Clark, Robert B., Major
Volume:
Language: English
Subject: Government publications, Armed Forces, Military law
Collection: Military Law Review
Subcollection:
Historic
Publication Date:
Publisher: Government Publication
QR link for Government Caused Delays in the Performance of Federal Contracts the Impact of the Contract Clauses
Add to Book Shelf
Flag as Inappropriate
Email this Book
 

Click To View

Other Books I Looked at: Click to view all Books in my History


  • Government Caused Delays in the Performa... (by )
    Book Rating (200)
Scroll Left
Scroll Right

Click To View

People also read these books: Click to view all Additional Books


  • Military Law Review-Volume 135 (by )
    Book Rating (175)
  • Military Law Renew-Volume 152 (by )
    Book Rating (200)
  • Military Law Review-Volume 142 (by )
    Book Rating (200)
  • Military Law Review-Volume 168 (by )
    Book Rating (155)
  • Military Law Review-Volume 151 (by )
    Book Rating (175)
  • The Militia and the Constitution: A Lega... (by )
    Book Rating (132)
  • Military Law Review-Volume 144 (by )
    Book Rating (200)
  • Military Law Review-Volume 134 (by )
    Book Rating (200)
  • Military Law Review-Volume 137 (by )
    Book Rating (200)
  • Military Law Review-Volume 169 (by )
    Book Rating (200)
  • Military Law Review-Volume 141 (by )
    Book Rating (175)
  • Military Law Review-Volume 146 (by )
    Book Rating (132)
Scroll Left
Scroll Right

Click To View

Other Books by Same Author: Click to view all books by Clark, Robert B., Major


  • Government Caused Delays in the Performa... (by )
    Book Rating (200)
Scroll Left
Scroll Right

Click To View

Other Books with Same Subject: Click to view all books in Government publications, Armed Forces, Military law


  • Balthazaris Ayalae de Jure et Officiis B... Volume Vol. 1 (by )
    Book Rating (132)
  • Balthazaris Ayalae de Jure et Officiis B... Volume Vol. 2 (by )
    Book Rating (118)
  • Das Heeresrecht der Osterreichisch-Ungar... (by )
    Book Rating (175)
  • Defensa Del General Toral : Ante El Cons... (by )
    Book Rating (200)
  • A Course of Instruction in Ordnance and ... (by )
    Book Rating (132)
  • A Manual for Courts-Martial, Courts of I... (by )
    Book Rating (200)
  • Frightfulness in Theory and Practice as ... (by )
    Book Rating (200)
  • Das Militar-Strafverfahren in Russland, ... (by )
    Book Rating (132)
  • Forms of Procedure for General and Summa... (by )
    Book Rating (132)
  • A Course of Instruction in Ordnance and ... (by )
    Book Rating (155)
Scroll Left
Scroll Right

 

Desktop View       Kiosk View

Copyright © World Public Library. All rights reserved. eBooks from World Public Library are sponsored by the World Public Library Association,
a 501c(4) Member's Support Non-Profit Organization, and is NOT affiliated with any governmental agency or department.